Term
Type of Contract where the contractor has the most risk?
Where owner has the most risk? |
|
Definition
Fixed price contract
Cost-reibursable contracts (Cost plus, GMP)
|
|
|
Term
Formula for determining $ surety obligations- Penal Sum? |
|
Definition
See pg 133 for example
unpaid balance = k amt - amt paid to contractor
Surety's obligation = Cost to complete - unpaid bal + liquidated dmgs
-only pay up to the Penal Sum which is original k amt |
|
|
Term
A third party beneficiary relationship that is incidental is sufficient to establish rights of recovery. |
|
Definition
False, an intended third party beneficiary relationship will establish rights of recovery
p 19-20 |
|
|
Term
What does Right to work state mean? Is TN a right to work state? |
|
Definition
This gives employees the power to decide for themselves whether they want to join or financially support a union
TN is a right to work state |
|
|
Term
lien laws- who can file? how long does it last? |
|
Definition
state and federal laws that ensure that people providing labor or materials for construction projects receive payment
a subcontractor on a residential project where GC has contract with owner cannot file a lien
lien lasts 1 year after work is finished in TN- must file it within 90 days |
|
|
Term
Thomas & Associates v. Metro Government of Nashville |
|
Definition
- No damages for delay clause- means there is only a time extension for delays- no $
-Courts are split on this issue and usually do not enforce it if delay was directly from owner actively interfering
-This case ruled in favor of owner (Metro)
|
|
|
Term
Type I vs. Type II differing site conditions
-definition, steps after, & proof |
|
Definition
Type I- something must be indicated in a certain way in the contract documents, and when encountered on site, found to be different- to claim contractor must show they relied on contract docs causing detriment
Type II- Something differs materially from conditions normally expected, must be of such an unusual nature that it could not have been predicted for that kind of project- must give notice to owner- forced to use additional $ due to condition |
|
|
Term
|
Definition
-Gives ruling that you cannot terminate without giving notice
-McClain was brick mason and when Kimbrough wasn't happy with mcclain's work, he went and hired another brick mason without telling McClain and breached contract |
|
|
Term
|
Definition
the existence of a contractual relationship- must demonstrate this before seeking damages in a lawsuit |
|
|
Term
Non enforceable Contracts- What constitutes? Examples? |
|
Definition
-Not legally enforceable if contract contemplates illegal activity, contrary to public policy, not executed by authorized person
-Example is an unlicensed contractor performing work |
|
|
Term
"Door Slamming" Policy- Is it enforced in TN? |
|
Definition
-dealing with the enforceability of a contract by an unlicensed contractor
-this policy says the contract is null and void, can't seek relief in court
-TN stops short of door slamming- allows recovery of documented expenses with convincing proof- no recovery of profits
-if contractor exceeds its limit, it is considered contracting without license- 10% allowance |
|
|
Term
Cost plus percentage fee contract- payment, when is it used, incentive? |
|
Definition
-Cost Plus- Owner reimburses contractor for work and then there is a fee that is stipulated in contract
-Actual costs plus 10% fee
-used when plans and specs are incomplete
-no incentive to control costs- good idea to hire CM
|
|
|
Term
GMP Contract- when is it used? |
|
Definition
-cost reibursable- cost of services + fee + contingency
-no payment givent to contractor over the GMP, owner keeps any savings if under the GMP
-plans and specs must be complete |
|
|
Term
Cost Plus Fixed Fee, when is it used, fee |
|
Definition
-reimburse actual cost plus a fixed fee determined as percentage of probable costs
-cost overrun no benefit to contractor
-used when plans and specs prohibit firm pricing |
|
|
Term
Cost plus incentive fee contract |
|
Definition
-cost reimbursable where fee is based on most probable cost
-owner and contractor split overrun/savings 50/50 |
|
|
Term
Competitive Bid/Lump sum contract- payment? risk? |
|
Definition
-not cost reimbursable (meaning its fixed price)
-contractor paid an agreed fixed price paid on a pro-rata (proportionate) basis based on % of completion
- Contractor assumes all the risk (but gets all the savings if under budget) |
|
|
Term
Schedule of Bid or Unit Price contract- kind of work where this is common |
|
Definition
-Usually limited to narrow scopes of work- utilities, earthwork
-estimated quantities with a fixed unit price
-payment depends on quantity of work performed during pay period |
|
|
Term
|
Definition
-Spearine performed work on a sewer exactly according to plans and specs- it is implied that the plans will be correct
-flood destroyed the sewer, but Spearine not responsible
-Ruling that contractors are not responsible for defects in plans and specs |
|
|
Term
Docs that usually comprise a construction contract |
|
Definition
-Bid documents, Integration/Merger (merges all prior negotiations into written contract), Plans and specs, general conditions, special conditions, addenda, surveys/geotech reports (physical conditions) |
|
|
Term
Common Red Flag Clauses (8) |
|
Definition
Dispute resolution, governing law, changes, differing site conditions, delays & suspensions, termination, notice exculpatory |
|
|
Term
Red Flag Clause: dispute resolution- time, procedure, sovereign immunity |
|
Definition
- general: precisely what steps the owner and contractor are required to take to resolve disputes
-Time limits- 21 days after occurence
-Procedural steps to follow -who is the initial decision maker (architect unless noted otherwise) -whether after there is mediation/arbitration/court
-steps to appeal decision
-sovereign immunity- meaning that contractor cannot sue in state court of law- must go to claims court run by the state and there is no appeal
|
|
|
Term
Red flag clause: Governing Law/Venue
TN Statute on governing law? |
|
Definition
-Venue- location of action
-Governing law- which state law applies - law of project location or location of architect's place of business?
-TN statute- if the project is located in TN, laws of TN are applied clause saying otherwise is void |
|
|
Term
|
Definition
-General: right of owner to change the contract unilaterally, places limitations on that right, contractor's duty to perform change (construction change directive), and contractor's right to be paid for performing change
- also architect has a right to change (minor) |
|
|
Term
red flag clause: Differing site conditions- limits, who determines, special case |
|
Definition
- Note the time limits
-the architect is to determine first
-applies to Type I and Type II site conditions
-article to suspend work if any human remains or archaeological sites are found |
|
|
Term
red flag clause: Delays & suspensions |
|
Definition
- excused or unexcused delay
- compensable or non-compensable
- Fed contract provisions are typically fair on delays beyond contractors control like acts of god and owner interference
-watch out for no damage for delay clause |
|
|
Term
Red flag clause: terminations- types, examples, notice |
|
Definition
-Termination for cause - examples: fails to provide sufficient labor, fails to pay subs, substantial breach of contract
-Must give written notice and opportunity to cure (A201 =7 days written notice)
-Take work over- owner completes work and back charges the contractor
-Also termination for convenience clause |
|
|
Term
Red Flag clause: Time (Notice), NTP, special case |
|
Definition
-Notice To Proceed- when they can start, where they can work, number of days to complete work
-delayed NTP causes contractor resource allocation problem
-"time is of the essence" - must have these exact words |
|
|
Term
Liquidated damages- what does it take to enforce? In TN? if contract is silent? |
|
Definition
- no proof of actual damage required
-not enforceable in some states- Enforced in TN if reasonable and not a penalty
-if there is no liquidated damage provision, owner can try to prove actual damages due to late completion |
|
|
Term
Moore v. Clarksville Case- One issue plus change order |
|
Definition
Issue of site availability
-Implied obligations:
-to timely make worksite available w/o restrictions
-not to interfere, hinder, or delay performance
-watch out for limitation on work time or restricted use of work site
-Moore was awarded for delays of no fault of its own- delays were bc co-prime contractor occupied site
-also written change order requirement waived in this case |
|
|
Term
Retention- what is it and its purpose? how much in TN |
|
Definition
-contract funds held by owner until satisfactory completion and acceptance of work
-5% of each progress payment in TN
- purpose is to create a fund to fix defective work or contract default |
|
|
Term
Red flag clause: Exculpatory clauses - examples, do courts enforce? |
|
Definition
- relieves a party of liability
-Examples: indemnification, no damages for delay, limitation of liability
-many courts are reluctant to enforce them because they are unecessarily harsh |
|
|
Term
Worker's comp-
- if sub fails to get WC |
|
Definition
- required by statute covering the liability of employees getting hurt on the job
-employee cannot sue (tort suit) if company has worker's comp
-required by law no matter how many employees a contractor has
-if a sub fails to get worker's comp, then higher tier contractor will be responsible |
|
|
Term
Comprehensive General Liability (CGL) Policy
- who obtains, what is it for, what triggers it
-what case? |
|
Definition
- the contractor obtains and pays premiums for the CGL
-it protects them from claims for personal injury or property damage by third parties resulting from defective workmanship
-triggered by an "occurrence"- meaning an accident resulting in injury that was not expected
-travelers v. moore - court held that there was an "occurence" and that travelers must defend moore |
|
|
Term
Builder's risk- Insurance
-who obtains, what is it for, how much is coverage worth
-named peril vs. all risk |
|
Definition
-owner will obtain
-protects against loss by an external cause (basically an act of god
-coverage is for value of work lost up to limit of policy
-named peril is specific things like fire, flood, etc
-all risk covers everything (except exclusions- review these exclusions!) |
|
|
Term
Errors & Omissions (E & O) Insurance
-who obtains, what is it |
|
Definition
-designers/engineers obtain this insurance
-Insurance that covers professional negligence of design professionals |
|
|
Term
Insurance Red Flags:
Endorsements
Deductible
subrogation
waiver of subrogation |
|
Definition
endorsement- expand coverage to include more things
deductible- amount insured pays out of pocket before policy kicks in
subrogation- when insurance company pays loss, and then tries to recover that money if they think someone was at fault (subs)
-waiver- prevents insurance company from getting back losses |
|
|
Term
Performance bond
-what is it for, what triggers coverage, principal & obligee |
|
Definition
-to ensure that the work is completed
-triggered by principal's (contractor) default- surety is obligated to make sure the work is completed in this case if the obligee (owner) has not breached contract |
|
|
Term
Surety
-response to default, options after |
|
Definition
-response- perform investigation- determine whether principal is truly in default & obligee breached contract
options- assist to remedy default, take control and hire another contractor, let owner complete the project by hiring another contractor then paying them excess costs
|
|
|
Term
Payment Bonds
-whats it for, who requires, (Little) Miller Act |
|
Definition
-surety of this bond guarantees payment to third parties- which protects private owner from lien claims
-the owner requires
-Miller Act makes payment bond mandatory on Fed gov. projects greater than $100K- little requires a payment bond on any public works project and state highway projects in TN |
|
|
Term
Express vs. Implied terms/obligations |
|
Definition
express- things that are explicitly stated in contract- strong wordings like must, shall
implied- not explicitly stated but implied- things like good faith and fair dealing (subjective) and implied good workmanship- no implications if express term says otherwise |
|
|
Term
Formal written requirement for change orders?
-cardinal change? |
|
Definition
-courts like the written requirement- definite understanding between parties, avoids controversies
-written requirement can be waived by conduct or course of dealing by both parties- once waived, cannot be revoked
-cardinal change is a drastic change in the scope- excessive small changes may be cardinal
|
|
|
Term
Construction Acceleration- types, impacts |
|
Definition
-voluntary acceleration- contractor chooses to accelerate- they have the burden of finishing on time, or want to finish early for incentive
-directed by owner- can't direct acceleration unless contract says so- if directed must compensate contractor
impacts- increased labor force, additional equip and material, resequencing, less efficient work, safety issues |
|
|
Term
Measured Mile Method (acceleration)-proving indirect costs - other method |
|
Definition
- production increased for known documented reason
-measure productivity over non-accel period and then measure productivity over accelerated period
- compare periods and interpolate accel costs - gives low and high estimate of total man hours- productivity loss
other method- total cost method- contractor claims 140% of contract and asks to get paid 40%- some courts do not accept |
|
|
Term
Contract Claim essentials - proving claim, notice & time |
|
Definition
- short descripition of claim
-contract provisions claim is based off of
-detailed desc. of extra work required and why
-prove claim with detailed documentation
- claim requires written notice that is within time limit |
|
|